Because of the extreme weather events that are often too hot, too dry or excessively rainy or wet in the summer. Therefore, it has never been considered a good season for home improvement. In fact, in the summer construction, it is only necessary to pay attention to some important issues and to avoid quality problems. Here, the living family Xiao Bian has specially collected the decoration information that suits the summer construction, hopefully will help you to install the satisfied love family this summer!
In recent years, with the vigorous development of the real estate industry, decoration has become another consumer hot spot in the life of urban and rural residents. However, due to the current non-standard home decoration market and the lack of consumer expertise, disputes caused by home improvement are on the increase. There are four main causes for such disputes.
Unclear understanding of the contractor’s qualifications
Mr. Ma commissioned Qiao to decorate his own home with a total price of 24,000 yuan. After completion, due to dissatisfaction with the quality of decoration, Mr. Ma paid only 12,000 yuan for renovation. To this end, Qiao Mou Ma will be brought to court. Because Qiaomou undertakes the decoration business externally in the name of individual decoration households, that is, it has not been approved for registration in accordance with the law, there is no business license issued by the industry and commerce department, and it does not have the legal qualification for contracting the decoration business abroad. The court therefore found that the decoration contract signed by both parties was invalid, and Qiao assumed the main responsibility. Mr. Ma also assumed certain fault liability for neglecting the examination of the plaintiff's contractual qualifications.
The State has strict qualification examination and permission for decoration contractors. However, in many places, especially small and medium-sized towns and rural areas, the qualifications of many contractors do not undertake the housing decoration business with the approval of the competent authority at all, and it is difficult to guarantee the decoration quality. And directly led to the decoration contract is invalid.
Do not pay attention to the housing renovation contract
In reality, some homeowners and renovation contractors have only reached an oral agreement to start construction; some even if the contract is concluded, but the contractual requirements are incomplete, in essence, a simple intention agreement; there are only pay attention to the decoration price , design drawings, renderings, and selected materials, but ignore important items such as quality, duration, and liability for breach of contract. After the dispute caused by the above-mentioned contract, the two parties often shirk their opinions, which will directly lead to the effective maintenance of the lawful rights and interests of the ordering party (homeowner).
Disputes caused by breach of contract by the bearer
The house decoration contract signed by Xu and a decoration company stipulated that the power line should be buried in a reasonable position around the wall. However, during the construction process, the decoration company arbitrarily changed the contract without the permission of the owner, and laid part of the lighting line on the surface of the wall. For this reason, Xu sued the decoration company to court. The court ordered the defendant to renovate according to the contract, and to compensate Xu economic loss of 2,400 yuan. The disputes caused by breach of contract by the contractor are mainly reflected in the following aspects: First, the project was not completed on time according to the date agreed in the contract; second, the material used for construction was inconsistent with the materials agreed in the contract; and thirdly, during the construction of the concealed project, it was not carried out according to the contract. If the contractor arbitrarily changes the layout of electricity lines, gas pipelines, and ventilation ducts, it may cause potential safety hazards in the future.
Homeowner's breach of contract triggers a dispute
Such disputes are mainly manifested in the fact that in the construction process, the ordering party violated the contractual agreement, frequent changes to the design drawings and the use of materials, additions and deletions of renovation projects, and delays in the payment of construction costs resulted in delays in the construction period. Humou commissioned the decoration company to decorate its house. The home improvement contract signed by the two parties agreed that Hu Mou should pay for the project in installments according to the construction progress. However, after the decoration company completed most of the projects according to the contract, Hu Mou only paid 3,000 yuan for the first phase of the project. To this end the decoration company will Humou sued the court, the court was ordered to Humou to pay the decoration company's engineering section 14,000 yuan.
Decoration Contract Home Decoration Precautions Decoration Precautions Decorate Decoration Company Home Home Decoration Design House Decoration Effect Picture
Industrial Aluminium Profiles,Aluminum Heat Sink Profile,Mobie Phone Base Aluminum Profile,Electrical Aluminum Extrusion Profile
Guangdong Jihua Aluminium Co., LTD , https://www.jihua-alu.com